Terms & Conditions

1. Scope
The present terms and conditions (Terms) govern the relationship between you as a customer and Pathworks GmbH, Nidfeldstrasse 5, 6010 Kriens (hereinafter Pathworks) for purchase of hardware and software and related services. The delivery area is limited currently to Switzerland and the Principality of Lichtenstein.

2. Conclusion
Your order reaches us in writing, via internet, phone or fax. Upon receipt we will send you an order confirmation or invoice. The specification of the order confirmation / invoice is a binding contract. Occurring to any deviations are telling us about your order immediately. Pathworks reserves the right to pass on price changes or product changes by the manufacturer to the customer. A withdrawal from the contract is possible only with our written consent. Here are the following amounts due for payment: Until 90 days before the scheduled delivery date 10%, to 60 days 20%, to 30 days 30% within 30 days before scheduled delivery and 40% after excretion to supply 50% of contract value.

3. Prices and Payment
The agreed prices are exclusive of shipping product, advanced recycling, insurance and installation costs. These costs will be calculated separately. Option 1: Delivery will be made only after full payment of the Kaufpreises.Variante 2: All delivered articles remain until full payment of the purchase price of property Pathworks. Pathworks is entitled to have the reservation of ownership in the property title registration of the canton of residence. We are not obliged to deliver a product at an incorrect (lower) price to you if the price error is obvious and unmistakeable and you could reasonably have a mis-pricing can be detected, even if we already sent an order confirmation with the wrong price have.

4. Delivery / Times
The delivery dates specified by Pathworks be considered without the express written warranty otherwise as guidelines only. Specifying a delivery date is given in good faith but without guarantee. This is particularly true in case of delivery delays on the part of the customer. Should be delayed a shipment of one of Pathworks writing promised delivery date out, then the customer may, upon expiry of by him in writing to be applied in an additional period of at least the weeks Pathworks give notice and to unused expiry of a deadline in 5 days in the wake of the relevant order . recede Further claims, especially claims for damages are, in each case ausgeschlossen.Bei delivery disruptions due to circumstances not attributable to the Pathworks has, such as Strikes, lockouts, material failure, promotion and operation of the lock manufacturer or transport problems, is entitled Pathworks, cancel confirmed orders. The customer is entitled to a refund in this case possibly a paid purchase price, further claims are excluded. If the customer is in acceptance delay, Pathworks can insist on the fulfillment and claim damages for delay or waiver within 10 days written notice to the subsequent performance and call for 20% of the sales price as a penalty. The assertion of further damages is reserved.

5. Return of products
You need to examine the delivered goods immediately upon receipt of your notice of contractual compliance and hidden defects immediately. Otherwise, the products delivered as approved. Basically, no right of return of products which the customer is due to wrong assumptions or ordered by mistake. As far as a gesture of goodwill Pathworks agrees return of products, these are to be returned in original condition in their original packaging, together with proof of return and proof of purchase. Return costs will be borne by you in this case. Products, which can no longer be sold as new goods are taken back to a lower value of 20% of the sales price of Pathworks. The application form for the return of products can be downloaded here (link)

6. Warranty
Pathworks does not warrant the products it supplies. The customer is only entitled to a warranty of the manufacturer, which is right to assert this or that of the designated sites. The customer may request the assignment of Pathworks possibly belonging to the latter warranty claims against third parties, and such claims by the customer at his own expense and risk to be asserted. Further claims by the customer are excluded. The Customer acknowledges that limited because of the applicable warranty of the manufacturer's warranty is usually chosen by the respective manufacturer / supplier of repair or replacement of defective / faulty products and also only applies if the products in Switzerland or the Principality Liechtenstein remain, and no repair attempts took place from third haben.Pathworks does in particular not to be responsible for defects caused by faulty installation by you or commissioned one of you third party, operator error, interference with or modification of products by you or by a non-authorized third party as well as on external influence on the products are due, and the suitability of products for a particular purpose; services that were provided according to your specifications.

7. Damage
Damage during transport as part of our transport insurance only be replaced if the damage is shown to us no later than within 6 days after delivery of the goods or in case of hidden damage immediately after discovery of the damage in writing.

8. Software
The conditions concerning the use of Pathworks delivered software products, programs, manuals and other documents addressed to the specific requirements for a software manufacturer, which in particular are included in the software license agreement between software producers and users / end-user.

9. Privacy Policy
Their data exposed in the course of handling the business relationship of electronic data processing: Pathworks comply with the provisions of the Federal Law on Data Protection.

10. Applicable law and jurisdiction.
It applies the laws of Switzerland. The validity of the United Nations Convention on Contracts for the International Sale of Goods of 11 April 1980 (CISG) is excluded. Jurisdiction is Kriens. For disputes arising from consumer agreements for customer complaints, the court at the domicile or headquarters of a party responsible for the actions of Pathworks court at the domicile of the defendant. Consumer agreements submitted contracts for services for personal or family needs of the customer are determined. For customers with a foreign residence or place of business Kriens is that the exclusive venue for all legal proceedings, subject differently denominated binding law.

11. Final Provisions
Pathworks reserves the right to change the terms at any time. Should any of these terms are invalid, this shall not affect the validity of the remaining provisions.

Kriens, 8 May 2009

Anschschrift: Pathworks GmbH, Nidfeldstrasse 5, CH-6010 Kriens
Phone: 041 318 4000
Fax: 041 318 4009